REP03942 - Laserfiche WebLink

Home Browse Search

use of the equipment, plant and other property of SUBCONTRACTOR which is associated with the WORK. Should SUBCONTRACTOR become insolvent or be placed in liquidation or under judicial management, CONTRACTOR may require full and wmglete assurance that satisfactory ' performance will wntinue to be achieved. CONTRACTOR shall be the sole judge of satisfactory performance and the adequacy of assurances thereof. Said full and complete assurances shall be provided within 72 hours of written request to SUBCONTRACTOR, unless ' a longer time is specifically allowed. Should, in CONTRACTOR'S sole judgment, the assurances be unsatisfactory, CONTRACTOR may, without process of law and without violating ' this CONTRACT, upon written notice take the prosecution of the WORK, or a portion thereof, away from the SUBCONTRACTOR and complete it as in the preceding paragraph. ' Upon taking over the WORK by CONTRACTOR, no further payment will be made to SUBCONTRACTOR until the WORK, or portion thereof, is completed or other arrangements satisfactory to CONTRACTOR are made. Any moneys due or that may become due ' SUBCONTRACTOR under this CONTRACT may be applied by CONTRACTOR to payment for labor, material, equipment, subcontracts, administrative expense and any other costs to CONTRACTOR in completing the WORK or which result from delays in completing the WORK. Should the expense incurred by CONTRACTOR in taking over and completing the WORK, or ' portion thereof, exceed the sum that would have become payable under the CONTRACT, then SUBCONTRACTOR (and SUBCONTRACTOR'S surety, if applicable) shall be liable to the CONTRACTOR for the amount of such excess. Should the expense incurred by CONTRACTOR be less than the sums that would have become payable, then SUBCONTRACTOR shall be entitled to a portion of the difference computed as follows. SUBCONTRACTOR shall be entitled to pro rata compensation for WORK ah eady performed ' not exceeding the reasonable cost of WORK done and materials supplied by SUB- CONTRACTOR to the time of termination plus an equitable profit on WORK completed, not exceeding the amount paid plus the difference noted above. No anticipated profits applicable ' to the unwmpleted portions of the WORK will be allowed. If CONTRACTOR should incorrectly terminate this CONTRACT for default or for breach, it ' shall be deemed to be a termination by CONTRACTOR for reasons other than cause, and payment shall be made as in the case of termination for convenience. In no event shall CONTRACTOR'S liability or SUBCONTRACTOR'S recovery under this Article exceed the total amount determined by application of ARTICLE GC-31.0, "SUSPENSION OR TERMINATION FOR CONVEATIENCE." GC-32.0 Not Used GC-33.0 LABOR AND PERSONNEL SUBCONTRACTOR shall employ only competent and skilled personnel to perform the WORK and shall be responsible for maintaining harmonious labor relations with its employees. ' SUBCONTRACTOR shall remove and replace unacceptable personnel determined to be ' 3-12