Laserfiche WebLink
<br />( <br /> <br />002204 <br /> <br />Durango Pumoing Plant - Stage 1 <br /> <br />3. <br /> <br />Following receipt of an executed contract modification, incorporate the activity <br />data and logic relationships stipulated in the modification into the current <br />schedule for inclusion in the next scheduled progress update. <br /> <br />~ <br /> <br />K. Time Impact Evaluation: <br /> <br />I. The Contracting Officer will use time impact evaluation to determine if a time <br />extension or reduction to the contract milestone dates is justified. <br /> <br />2. Provide a time impact evaluation for any contract change, e.g., a change order, <br />proposed modification, or value engineering proposal. Provide a time impact <br />evaluation to support a claim or request for an equitable adjustment to the contract <br />which involves a delay or accelerated schedule. <br /> <br />3. A time impact evaluation is applicable whether the Contractor's current schedule <br />milestone dates are the same as, earlier, or later than, those required under the <br />contract. <br /> <br />4. Changes, additions, or deletions to activities; activity durations; or activity time <br />frames will not automatically mean that an extension or reduction of contract time <br />is warranted or due the Contractor. <br /> <br />5. Time extensions for performance will be considered only to the extent that the <br />Contractor's current scheduled milestone dates exceed the contract milestone <br />dates. <br /> <br />For all activities directly affected by the change or delay, include the current and <br />proposed items: <br /> <br />a. Activity description. <br /> <br />b. Type and quantities of major pieces of equipment, principal manpower, <br />and pacing material. <br /> <br />c. Activity duration. <br /> <br />d. Eatnings. <br /> <br />e. A narrative containing the rationale used in developing the proposed logic <br />relationships and activity data. <br /> <br />7. Float is not for the exclusive use by or benefit of either the Government or the <br />Contractor, <br /> <br />6. <br /> <br />8. Prepare a single time impact evaluation for all modifications issued after Notice to <br />Proceed (NTP) and prior to approval of the baseline schedule. Submit the time <br />impact evaluation with the first progress update. <br /> <br />9. Perform time impact evaluations using data in the most recent approved schedule <br />prior to change or delay event. <br /> <br />a. Prepare proposed revised schedule and narrative description describing <br />and highlighting where changes or delays will be included.r <br />Construction Program <br />01321 - 5 <br />