WSPC07461 - Laserfiche WebLink

Home Browse Search

002235 Durango Pumoing Plant - Stage I b. Prepare table comparing the results of two mathematical analyses: One using current schedule data from the last approved schedule prior to event requiring evaluation, and one using proposed schedule data incorporating the changes or delays. I) Show contract milestones and activities whose periods of performance have shifted as a result of any change which affects production and/or manufacture schedules, material orders, construction seasons, and labor and/or equipment utilization. 2) Base mathematical analyses on status of work and available float at the time the Contracting Officer directs or proposes a change to the work, the Contractor submits a value engineering proposal, or when a delay occurs. ~- - If 1.07 REVIEW AND EVALUATION A. Baseline Schedule: 1. Within 20 calendar days after receipt of baseline schedule: a. Contracting Officer will accept or reject the proposed baseline schedule. b. Upon request from the Contracting Officer, meet with Contracting Officer's Representative(s) for a joint review of the proposed baseline schedule. c. If schedule is rejected, revise and resubmit within 7 calendar days following the date of the rejection letter. 2. Do not proceed with onsite work, except mobilization and surveying, until baseline schedule has been approved by the Goverrunent. B. Updated schedules: I. The Government will require 7 calendar days after receipt of each monthly update to review and approve or reject the updated schedule. 2. If the updated schedule is rejected, revise and resubmit updated schedule within 7 calendar days following the date of the rejection letter. 1.08 FAILURE TO COMPLY A. Failure to comply with the requirements of this section shall be grounds for a determination by the Contracting Officer that the Contractor is not prosecuting the work with sufficient diligence to ensure completion within the specified time. PART 2 PRODUCTS Not Used Construction Program 01321 .6