WSP05493

• File Number: 8146.100
• Description: Pueblo Dam - Project Description
• State: CO
• Basin: Arkansas
• Water Division: 2
• Date: 6/1/1964
• Author: US DoI BoR
• Title: Schedule General Provisions Specifications and Drawings - Initial Construction For Pueblo Dam
• Water Supply Pro - Doc Type: Report/Study

2375

.

subcontract hereunder which exceeds $100,000.

18. COMMENCEMENT, PROSECUTION,
AND COMPLETION OF WORK

'.

a. Completion period.- The contractor shall begin
work within thirty (30) calendar days after date of
receipt of notice to proceed, and shall complete the
parts of the work as described below by the dates
specified or within the number of calendar days
stated below from the date of receipt of such
notice: Provided, That the period allowed for the
completion of Part (4) below shall be reduced by
one (1) calendar day for each calendar day in excess
of ten (10) calendar days. or any extension thereof.
elapsing between the contractor's receipt of and
return of properly executed contract, and
performance and payment bonds as required in the
Bid Form (Standard Form 21).

~

Part (1 I.-Completion of the concrete plug
. ................... May 1, 1971

Part (2}.-Completion of excavation for concrete
dam, as described in Paragraph 65, and
completion of all clearing . . . . . . . . . . . . . .
. ............... . September 1 1971

.

Part (3).-AII contract work to the left of the
concrete plug . . . . . . . . . . . .
. ...,............. October 1,1971

Part (4).-The remainder of the work.

660 days

..

The data and drawings required to be submitted for
approval under these specifications are described in
Paragraphs 57, 115, 132, 137 and 141. The
contracting officer will require forty (40) calendar
days for approval of each submittal of data or
drawings to be submitted by the contractor or for
approval of each corrected resubmittal. If the
contracting officer uses time in excess of the
above-stated number of days to approve any
submittal, the excess time will be added to the time
allowed the contractor for completion of the work
alfected by such excess time: Provided, That if
approvals by the contracting officer of two or more
separate submittals or resubmittals are late and
result in concurrent days of excess time such days
will be counted only once in computing extension
of the completion date. The number of calendar
days required for approval of data or drawings will
include the date the data or drawings are received
by the contracting officer and will extend through

('.

.

Par. 17

the date of return mailing to the contractor either
approved or for correction.

b. Prosecution of the work.-The capacity of the
contractor's construction plant, sequence of
operations, method of operation, and the forces
employed shall, at all times during the continuance
of the contract, be subject to the approval of the
contracting officer and shall be such as to insure the
completion of the work within the specified period
of time.

c. Priorities.-If performance under these
specifications is delayed by operations of any
United States national priorities or material
allocation system, the time for performance will be
extended to compensate for such delays.

19. L10UIDATED DAMAGES

In case of failure on the part of the contractor to
complete the work within the time fixed in the
contract or any extensions thereof, the contractor shall
pay to the Government as fixed, agreed and liquidated
damages, pursuant to the clause of this contract
entitled "Termination for Default-Damages for
Delay-Time Extensions," the following amounts per
day for each calendar day's delay in the completion of
the T~peet~~e parts of the work as subdi~ided in
Subparagraph 18a.:

Part (1).-Seven hundred and fifty dollars ($750).

Part (2).-Seven hundred and fifty dollars ($750).

Part (3).-Seven hundred and fifty dollars ($750).

Part (4l.-Five hundred dollars 1$500).

Provided that if liquidated damages are assessed on
more than one part at a time, the amount of liquidated
damages assessed will not exceed a total of one
thousand five hundred dollars ($1,500) per day.

Also see Paragraph 20 for liquidated damage. to be
assessed for late submittal of construction program.

20. CONSTRUCTION PROGRAM

Within forty.five (451 calendar days after date of
receipt of notice of award of contract. the contractor
shall submit to the authorized representative of the
contracting officer for approval a complete and
practicable construction program. The construction
program shall show in detail his proposed program of

11