Laserfiche WebLink
D011 FORM17 NO. 85 <br />REV.JULY 1979 <br />Page 8 <br />the performance of this contract, or by reason of any failure on the part of <br />said Principal, his agents, servants oremployees,hissub-contractororsub- <br />contractors, or any oC them, in the performance of said contract or any <br />portion thereof, and if the said Principal, his sub-contractor or sub- <br />con tractors, and each and all of them, shall duly pay for all labor, materials, <br />and other supplies used or consumed in the performance of the work <br />contracted to be done or any part thereof, these presents shall become void, <br />otherwise to be and remain in full force and effect. <br />THE STATE OF COLORADO shall be under no obligation, except as <br />expressly provided by statute, to withhold any sums due the said Principal <br />under the terms of this contract, or to protect in any other way the surety or <br />sureties, claimants or others. <br />No representation or statement of the Principal...... made to the surety or <br />sureties in application for this bond, or otherwise, shall be read into or be a <br />part of this bond or binding in any way on the obligee herein. <br />No assignment by Principal to surety of the proceeds of such contract shall <br />be binding, except as to any net surplus after paying all claims chargeable <br />bylaw or by said contract, against the proceeds thereof. <br />No extension of time of performance of said contract or delay in the <br />completion of the work thereunder shall invalidate this bond or release the <br />liability of the surety thereunder. . <br />This agreement shall notbe deemed valid until it shall have been approved <br />by the Controller of the State of Colorado, or such assistant as he may <br />designate. <br />IN WITNESS WHEREOF, Wehavehcreunto setourhands and seals at <br />T: <br />.Grand Junction, Colorado <br />the day and date above written. <br />Contractor: UNITED C PA F MESA COUNTY <br />sy: - <br />Bonding Co: UNITED~STATES F~DELITYdeRt <br />AND GUARANTY COMPANY <br />nyce R. Rotunno, <br />tary <br />Address: P. o <br />Bonding Agent:(Beck ~ -Pot ns ance, Inc. <br />By: <br />Attorney-in-Fact <br />Address: P•o. Isbx ]729 <br />p Grand .Junction, CO 81502 <br />App 20th by the STATE OoCTOBE0RAD0, epar men o ig ways, <br />This ............................. day of ........................................................................................ <br />A.D. 19....8$....: ~l <br />'By .......................................?rte?':... ~~ <br />Chi Engineer, ivision of <br />