Laserfiche WebLink
<br />" - 2 ? " n <br />uJ ...UJ <br /> <br />Durango Pomping Plant - Stage I <br /> <br />Amendment 00 I <br /> <br />2. Concurrent days of excess review time resulting from the Government's review of <br />two or more separate submittals or resubmittals will be counted only once in <br />extending the contract completion date. <br /> <br />3. No time extension will be allowed if the Contractor fails to make complete <br />approval submittals in sequence and within time periods specified. <br /> <br />4. Adjustment for Government delay will be made only to the extent that: <br /> <br />a. Government approval was required under the contract, and <br /> <br />b. Requests for approval were properly and timely submitted and were <br />approved. <br /> <br />5. Adjustment will be subject to terms of paragraphs (b) and (c) of the clause <br />"Suspension of Work," however, no such delay shall be deemed to be a <br />"suspension order" as the term is used in that clause. <br /> <br />C. Return of Submittals: <br /> <br />1. One set of submittals required for approval will be returned either approved, not <br />approved, or conditionally approved. <br /> <br />2. Submittals not approved: <br /> <br />, <br />{ <br /> <br />Revise and resubmit for approval. <br /> <br />Show changes and revisions with revision date. <br /> <br />Describe reasons for significant changes in transmittal letter. <br /> <br />Resubmit returned submittals within 30 days after receiving the <br />Government's comments, unless otherwise specified. <br /> <br />e. Requirements for initial submittals apply to resubmittals. <br /> <br />3. Do not change designs without approval of the Contracting Officer after approval <br />drawings, documentation, and technical data have been approved. <br /> <br />b. <br /> <br />a. <br /> <br />c. <br /> <br />d. <br /> <br />1.06 TRANSMITTAL <br /> <br />A. Send submittals required by Table 01330A - List of Submittals, to following addresses: <br /> <br />I. Contracting Officer, Bureau of Reclamation, Attn: UC-845, 125 South State <br />Street, Room 6107, Salt Lake City UT 84138-1147. <br /> <br />2. Construction Engineer, Bureau of Reclamation, FCO - ALP Division, PO Box <br />5107, Durango CO 81301. <br /> <br />3. Technical Service Center, Bureau of Reclamation, Attn D-8l60, PO Box 25007, <br />Denver CO 80225. <br /> <br />B. Send a copy of each transmittal letter to offices listed above which are not sent the <br />submittal. <br /> <br />Sobmittals <br />01330 - 3 <br />