PROJ00370 - Laserfiche WebLink

Home Browse Search

I I I I I I I I I I I I I I I I I I I neglect or carelessness, act or omission, on the part of said Principal, his agents, servants or employees, his sub-contractor or sub-contractors or any of them, in the performance of said contract or any portion thereof, and if the said Principal, his sub-contractor or sub-contractors, and each and all of them shall duly pay for all labor, materials, team hire, sustenance, provisions, provender, and other supplies used or consumed in the performance of the work contracted to be done or any part thereof, these presents shall become void, otherwise to be and remain in full force and effect. THE STATE OF COLORADO, COLORADO-UTE, PLATTE RIVER, SALT RIVER PROJECT and TRI-STATE shall be under no obligations, except as expressly provided by statute, to withhold any sums due the said Principal under the terms of this contract, or to protect any other way the sure~y or sureties, claimants or others. No representation or statement of the Principal made to the surety or sureties in application for this bond, or otherwise, shall be read into or be a part of this bond or binding in any way on the obligees herein. flo assignment by Principal to surety of the proceeds of such contract shall be binding, except as to any net surplus after paying all claims chargeable by law or by said contract, against the proceeds thereof. No extension of time of performance of said contract or delay in the com- pletion of the work thereunder shall invalidate this bond or release the liabil- ity of the surety thereunder including a warranty period of not less than two (2) years unless otherwise stated. This agreement shall not be deemed valid until it shall have been approved by the Controller of the State of Colorado, or such assistant as he may designate. ~ proceeds which become tayable to the STATE OF COLORADO, COLORADO-UTE, PLATTE RIVER, SALT RIVER PROJEC and TRI-STATE under this bond shall be divided and paid severally in the following proportions: 10 THE STATE OF COLORADO TO COLORADO-UTE TO PLATT RIVER TO SALT R I V ER PRO.] ECT TO TRI-STATE " " % % " 10 % IN WITNESS WHEREOF, We have hereunto set our hands and seals at the day and date above written. Principal Surety D-2